Contract Clause for Weather Delays Does Not Override Suspension of Work Clause
By EsqSocial Corporation 27/01/21
In the recent case of Granite Construction Co., ASBCA 62281, the Armed Services Board of Contract Appeals granted partial summary judgment to a contractor that sought delay damages under FAR 52.242-14, Suspension of Workâovercoming the Government's argument that the delays were contemplated under a separate clause for adverse weather delays....
By: Davis Wright Tremaine LLP